CERC Grants 100 Per Cent ISTS Waiver to 50 MW Hybrid Project
POWER & RENEWABLE ENERGY

CERC Grants 100 Per Cent ISTS Waiver to 50 MW Hybrid Project

The Central Electricity Regulatory Commission (CERC) has extended the Scheduled Commercial Operation Date (SCOD) of a 50 MW wind-solar hybrid project developed by AMPIN Energy Green and AMPIN Energy Green Three to February 28, 2026. It also granted a 100 per cent waiver of Inter-State Transmission System (ISTS) charges, treating the project as eligible for the relief available to renewable energy projects operational by June 30, 2025.

The decision was issued in Petition No. 228/MP/2026 after CERC examined delays in transmission infrastructure required to connect the project to the interstate network. The project was planned for connection at the Fatehgarh-IV ISTS Pooling Station, but its commercial operation was delayed because the associated substation was unavailable.

The generating facility and dedicated transmission lines were substantially completed and ready before the eligibility cut-off. However, the Fatehgarh-IV ISTS substation was commissioned by the Central Transmission Utility of India only on January 31, 2026, preventing the project from meeting its original operating schedule.

After the substation became available, AMPIN Energy completed the remaining testing and commissioning work within 28 days. The project achieved commercial operation on February 27, 2026, while February 28 was formally recognised as the revised SCOD for the regulatory relief.

A specially constituted CERC committee reviewed the developers’ request, conducting a prudence check of the delay, project readiness and commissioning period. It found that the developers had exercised due diligence and that the 28-day period was reasonable and consistent with industry practice. CERC accepted the committee’s recommendations under Regulation 13(2)(h) of the 2020 regulations, which permits extensions when renewable energy projects are delayed by unavailable transmission systems. The Commission consequently approved the SCOD extension and complete ISTS charge waiver, disposing of the petition.

The Central Electricity Regulatory Commission (CERC) has extended the Scheduled Commercial Operation Date (SCOD) of a 50 MW wind-solar hybrid project developed by AMPIN Energy Green and AMPIN Energy Green Three to February 28, 2026. It also granted a 100 per cent waiver of Inter-State Transmission System (ISTS) charges, treating the project as eligible for the relief available to renewable energy projects operational by June 30, 2025. The decision was issued in Petition No. 228/MP/2026 after CERC examined delays in transmission infrastructure required to connect the project to the interstate network. The project was planned for connection at the Fatehgarh-IV ISTS Pooling Station, but its commercial operation was delayed because the associated substation was unavailable. The generating facility and dedicated transmission lines were substantially completed and ready before the eligibility cut-off. However, the Fatehgarh-IV ISTS substation was commissioned by the Central Transmission Utility of India only on January 31, 2026, preventing the project from meeting its original operating schedule. After the substation became available, AMPIN Energy completed the remaining testing and commissioning work within 28 days. The project achieved commercial operation on February 27, 2026, while February 28 was formally recognised as the revised SCOD for the regulatory relief. A specially constituted CERC committee reviewed the developers’ request, conducting a prudence check of the delay, project readiness and commissioning period. It found that the developers had exercised due diligence and that the 28-day period was reasonable and consistent with industry practice. CERC accepted the committee’s recommendations under Regulation 13(2)(h) of the 2020 regulations, which permits extensions when renewable energy projects are delayed by unavailable transmission systems. The Commission consequently approved the SCOD extension and complete ISTS charge waiver, disposing of the petition.

Related Stories

Gold Stories

Next Story
Real Estate

Shree Naman Group acquires JW Marriott Bengaluru, Crowne Plaza Pune

Shree Naman Group has completed the acquisition of JW Marriott Bengaluru for Rs 16.11 billion and Crowne Plaza Pune for Rs 1.89 billion, taking its hospitality portfolio beyond Mumbai into two key business and hospitality markets.The Rs 18 billion transaction was completed on 1 October 2026, within 30 days of approval by the National Company Law Tribunal (NCLT) on 3 September 2026, following a competitive bidding process.The two hotels join the Group’s existing properties in Mumbai: Sofitel Mumbai BKC, Lemon Tree Hotel, Kalina BKC, and ibis Mumbai BKC. The portfolio now comprises five operat..

Next Story
Real Estate

Sobha Realty marks fourth year of IIFA partnership

Sobha Realty has reaffirmed its association with the International Indian Film Academy (IIFA) for the fourth consecutive year, returning as Title Sponsor of IIFA Weekend and Co-Presenting Sponsor of the IIFA Awards 2027. At a press conference in Mumbai, the UAE-based developer also highlighted its expansion into Abu Dhabi and its growing international presence.The upcoming IIFA Weekend and Awards will be held on 22 and 23 January 2027 at Etihad Arena, Yas Island, Abu Dhabi. The partnership, which began in Abu Dhabi in 2023, provides the developer with a platform to engage with Indian audiences..

Next Story
Technology

Powerplay Records 4X Growth in Platform Spend with AI Adoption

Construction technology platform Powerplay has reported up to fourfold growth in platform spending among customers adopting its artificial intelligence (AI) agents over approximately 18 months. The growth reflects increased adoption of AI-driven procurement and financing solutions among contractors and builders across India.The Bengaluru-based company has introduced an AI workforce designed to automate procurement coordination, supplier comparisons, material tracking and financing documentation. Its AI Purchase Executive enables contractors to compare supplier prices, monitor material requirem..

Advertisement

Subscribe to Our Newsletter

Get daily newsletters around different themes from Construction world.

STAY CONNECTED

Advertisement

SPECIAL OFFER
QR Code