+
CERC approves compensation for GST rate hike to RE developer
POWER & RENEWABLE ENERGY

CERC approves compensation for GST rate hike to RE developer

The Central Electricity Regulatory Commission (CERC) has granted approval to a renewable energy developer for seeking compensation to counteract the financial and commercial repercussions arising from changes in law events due to an escalation in the rates of goods and service tax (GST).

The developer is entitled to claim carrying costs, calculated at the minimum of the actual interest rate, the rate specified in the renewable energy tariff regulations, or the late payment surcharge rate stipulated in the power purchase agreement (PPA).

Ostro Energy, a subsidiary of ReNew Power Services, specialises in the development, operation, and maintenance of large-scale grid-connected solar power projects for wind power generation.

The power purchase agreement (PPA) for the 50 MW wind energy project was executed with the Solar Energy Corporation of India (SECI) on October 25, 2019. The Scheduled Commercial Operation Date was set for April 18, 2021. The alteration in GST rates occurred on October 1, 2021.

On June 12, 2022, the company filed a petition seeking compensation to alleviate the financial impact resulting from changes in law events related to the GST rate increase from 5% to 12%.

The petitioner urged the respondent to provide compensation, either as a one-time lump sum payment or through tariff adjustments, in response to the GST tax rate hike. Additionally, it sought interest or carrying costs from the date of incurring the expense until the Commission's order. The respondents in this matter are SECI and Uttar Pradesh Power Corporation (UPPCL).

The Commission noted that Article 12 of the PPAs stipulates that any statutory change in the tax structure affecting the wind power project constitutes a change in law. Recognising that the GST rates changed post the scheduled commercial operation date and considering the principle that change in law compensation should not result in profit, the Commission determined that the discount rate and annuity period would be the appropriate methodology for calculating change in law compensation.

The Commission decided that the liability of the respondents for monthly annuity payments commences from the 60th day from the date of the order or the date of claim submission by the petitioner, whichever is later. In case of delayed monthly annuity payments beyond the 60th day, a late payment surcharge is applicable.

Furthermore, the Commission ruled that Ostro Energy is eligible for carrying costs at the lowest of the actual interest rate paid, the rate of interest on working capital as per applicable renewable energy tariff regulations, or the late payment surcharge rate as per the PPA. Recently, CERC determined that the delay in adopting the tariff order by the Uttar Pradesh Power Corporation is a valid reason to claim an extension in the commissioning date for a wind energy project.

The Central Electricity Regulatory Commission (CERC) has granted approval to a renewable energy developer for seeking compensation to counteract the financial and commercial repercussions arising from changes in law events due to an escalation in the rates of goods and service tax (GST). The developer is entitled to claim carrying costs, calculated at the minimum of the actual interest rate, the rate specified in the renewable energy tariff regulations, or the late payment surcharge rate stipulated in the power purchase agreement (PPA). Ostro Energy, a subsidiary of ReNew Power Services, specialises in the development, operation, and maintenance of large-scale grid-connected solar power projects for wind power generation. The power purchase agreement (PPA) for the 50 MW wind energy project was executed with the Solar Energy Corporation of India (SECI) on October 25, 2019. The Scheduled Commercial Operation Date was set for April 18, 2021. The alteration in GST rates occurred on October 1, 2021. On June 12, 2022, the company filed a petition seeking compensation to alleviate the financial impact resulting from changes in law events related to the GST rate increase from 5% to 12%. The petitioner urged the respondent to provide compensation, either as a one-time lump sum payment or through tariff adjustments, in response to the GST tax rate hike. Additionally, it sought interest or carrying costs from the date of incurring the expense until the Commission's order. The respondents in this matter are SECI and Uttar Pradesh Power Corporation (UPPCL). The Commission noted that Article 12 of the PPAs stipulates that any statutory change in the tax structure affecting the wind power project constitutes a change in law. Recognising that the GST rates changed post the scheduled commercial operation date and considering the principle that change in law compensation should not result in profit, the Commission determined that the discount rate and annuity period would be the appropriate methodology for calculating change in law compensation. The Commission decided that the liability of the respondents for monthly annuity payments commences from the 60th day from the date of the order or the date of claim submission by the petitioner, whichever is later. In case of delayed monthly annuity payments beyond the 60th day, a late payment surcharge is applicable. Furthermore, the Commission ruled that Ostro Energy is eligible for carrying costs at the lowest of the actual interest rate paid, the rate of interest on working capital as per applicable renewable energy tariff regulations, or the late payment surcharge rate as per the PPA. Recently, CERC determined that the delay in adopting the tariff order by the Uttar Pradesh Power Corporation is a valid reason to claim an extension in the commissioning date for a wind energy project.

Next Story
Infrastructure Urban

India to Invest Rs 600 Billion to Upgrade 1,000 ITIs

As part of its drive to modernise vocational training, the Ministry of Skill Development and Entrepreneurship (MSDE), in collaboration with Gujarat’s Labour and Employment Department, held a State-Level Workshop at the NAMTECH Campus within IIT-Gandhinagar to discuss the National Scheme for ITI Upgradation.The consultation brought together key stakeholders from industry and the training ecosystem to align expectations and support implementation of the scheme, which aims to transform 1,000 Industrial Training Institutes (ITIs) across India using a hub-and-spoke model. The total outlay stands ..

Next Story
Infrastructure Urban

India Unveils Rs 600 Billion Maritime Finance Push

The Ministry of Ports, Shipping & Waterways (MoPSW) hosted the Maritime Financing Summit 2025 in New Delhi, bringing together over 250 stakeholders including policymakers, industry leaders, global investors, and financial institutions. The summit, held under the ambit of Maritime Amrit Kaal Vision (MAKV) 2047, focused on transforming India into a leading maritime power with strengthened financial, infrastructural, and technological capabilities.Union Minister Sarbananda Sonowal emphasised India's strategic progress, noting that average port turnaround times have dropped from four days to u..

Next Story
Infrastructure Urban

Govt Allocates Rs 500 Million To Boost Community Radio

The Central Government, through its ‘Supporting Community Radio Movement in India’ scheme, has allocated Rs 500 million to strengthen the community radio ecosystem across the country. The initiative aims to assist both newly established and long-operational Community Radio Stations (CRSs), ensuring their relevance to local educational, social, cultural, and developmental needs.According to the policy published by the Ministry of Information and Broadcasting, CRSs may be set up by not-for-profit organisations with at least three years of demonstrated community service. These stations are ex..

Advertisement

Subscribe to Our Newsletter

Get daily newsletters around different themes from Construction world.

STAY CONNECTED

Advertisement

Advertisement

Advertisement

Talk to us?